Public Contract Code, declared subset

Section 1100§Sections

“Public entity,” as used in this part, means the state, county, city, city and county, district, public authority, public agency, municipal corporation, or any other political subdivision or public corporation in the state.

(Added by Stats. 1982, Ch. 1120, Sec. 3.)

Section 1100.7§Sections

This code is the basis of contracts between most public entities in this state and their contractors and subcontractors. With regard to charter cities, this code applies in the absence of an express exemption or a city charter provision or ordinance that conflicts with the relevant provision of this code.

(Added by Stats. 2001, Ch. 832, Sec. 1. Effective January 1, 2002.)

Section 1101§Sections

“Public works contract,” as used in this part, means an agreement for the erection, construction, alteration, repair, or improvement of any public structure, building, road, or other public improvement of any kind.

(Added by Stats. 1982, Ch. 1120, Sec. 3.)

Section 1102§Sections

“Emergency,” as used in this code, means a sudden, unexpected occurrence that poses a clear and imminent danger, requiring immediate action to prevent or mitigate the loss or impairment of life, health, property, or essential public services.

(Added by Stats. 1994, Ch. 803, Sec. 1. Effective January 1, 1995.)

Section 1103§Sections

“Responsible bidder,” as used in this part, means a bidder who has demonstrated the attribute of trustworthiness, as well as quality, fitness, capacity, and experience to satisfactorily perform the public works contract.

The Legislature finds and declares that this section is declaratory of existing law.

(Added by Stats. 1999, Ch. 972, Sec. 2. Effective January 1, 2000.)

Section 1104§Sections

No local public entity, charter city, or charter county shall require a bidder to assume responsibility for the completeness and accuracy of architectural or engineering plans and specifications on public works projects, except on clearly designated design build projects. Nothing in this section shall be construed to prohibit a local public entity, charter city, or charter county from requiring a bidder to review architectural or engineering plans and specifications prior to submission of a bid, and report any errors and omissions noted by the contractor to the architect or owner. The review by the contractor shall be confined to the contractor’s capacity as a contractor, and not as a licensed design professional.

(Added by Stats. 1999, Ch. 875, Sec. 1. Effective January 1, 2000.)

Section 4100§Sections

This chapter may be cited as the “Subletting and Subcontracting Fair Practices Act.”

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4101§Sections

The Legislature finds that the practices of bid shopping and bid peddling in connection with the construction, alteration, and repair of public improvements often result in poor quality of material and workmanship to the detriment of the public, deprive the public of the full benefits of fair competition among prime contractors and subcontractors, and lead to insolvencies, loss of wages to employees, and other evils.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4103§Sections

Nothing in this chapter limits or diminishes any rights or remedies, either legal or equitable, which:

(a) An original or substituted subcontractor may have against the prime contractor, his or her successors or assigns.

(b) The state or any county, city, body politic, or public agency may have against the prime contractor, his or her successors or assigns, including the right to take over and complete the contract.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4104§Sections

Any officer, department, board, or commission taking bids for the construction of any public work or improvement shall provide in the specifications prepared for the work or improvement or in the general conditions under which bids will be received for the doing of the work incident to the public work or improvement that any person making a bid or offer to perform the work, shall, in his or her bid or offer, set forth:

(a) (1) The name, the location of the place of business, the California contractor license number, and public works contractor registration number issued pursuant to Section 1725.5 of the Labor Code of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvement, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specially fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of 1 percent of the prime contractor’s total bid or, in the case of bids or offers for the construction of streets or highways, including bridges, in excess of one-half of 1 percent of the prime contractor’s total bid or ten thousand dollars ($10,000), whichever is greater.

(2) An inadvertent error in listing the California contractor license number or public works contractor registration number provided pursuant to paragraph (1) shall not be grounds for filing a bid protest or grounds for considering the bid nonresponsive if the corrected contractor’s license number is submitted to the public entity by the prime contractor within 24 hours after the bid opening and provided the corrected contractor’s license number corresponds to the submitted name and location for that subcontractor.

(3) (A) Subject to subparagraph (B), any information requested by the officer, department, board, or commission concerning any subcontractor who the prime contractor is required to list under this subdivision, other than the subcontractor’s name, location of business, the California contractor license number, and the public works contractor registration number, may be submitted by the prime contractor up to 24 hours after the deadline established by the officer, department, board, or commission for receipt of bids by prime contractors.

(B) A state or local agency may implement subparagraph (A) at its option.

(b) The portion of the work that will be done by each subcontractor under this act. The prime contractor shall list only one subcontractor for each portion as is defined by the prime contractor in his or her bid.

(Amended by Stats. 2017, Ch. 28, Sec. 90. (SB 96) Effective June 27, 2017.)

Section 4104.5§Sections

(a) The officer, department, board, or commission taking bids for construction of any public work or improvement shall specify in the bid invitation and public notice the place the bids of the prime contractors are to be received and the time by which they shall be received. The date and time shall be extended by no less than 72 hours if the officer, department, board, or commission issues any material changes, additions, or deletions to the invitation later than 72 hours prior to the bid closing. Any bids received after the time specified in the notice or any extension due to material changes shall be returned unopened.

(b) As used in this section, the term “material change” means a change with a substantial cost impact on the total bid as determined by the awarding agency.

(c) As used in this section, the term “bid invitation” shall include any documents issued to prime contractors that contain descriptions of the work to be bid or the content, form, or manner of submission of bids by bidders.

(Amended by Stats. 2002, Ch. 204, Sec. 1. Effective January 1, 2003.)

Section 4105§Sections

Circumvention by a general contractor who bids as a prime contractor of the requirement under Section 4104 for him or her to list his or her subcontractors, by the device of listing another contractor who will in turn sublet portions constituting the majority of the work covered by the prime contract, shall be considered a violation of this chapter and shall subject that prime contractor to the penalties set forth in Sections 4110 and 4111.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4106§Sections

If a prime contractor fails to specify a subcontractor or if a prime contractor specifies more than one subcontractor for the same portion of work to be performed under the contract in excess of one-half of 1 percent of the prime contractor’s total bid, the prime contractor agrees that he or she is fully qualified to perform that portion himself or herself, and that the prime contractor shall perform that portion himself or herself.

If after award of contract, the prime contractor subcontracts, except as provided for in Sections 4107 or 4109, any such portion of the work, the prime contractor shall be subject to the penalties named in Section 4111.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4107§Sections

A prime contractor whose bid is accepted may not:

(a) Substitute a person as subcontractor in place of the subcontractor listed in the original bid, except that the awarding authority, or its duly authorized officer, may, except as otherwise provided in Section 4107.5, consent to the substitution of another person as a subcontractor in any of the following situations:

(1) When the subcontractor listed in the bid, after having had a reasonable opportunity to do so, fails or refuses to execute a written contract for the scope of work specified in the subcontractor’s bid and at the price specified in the subcontractor’s bid, when that written contract, based upon the general terms, conditions, plans, and specifications for the project involved or the terms of that subcontractor’s written bid, is presented to the subcontractor by the prime contractor.

(2) When the listed subcontractor becomes insolvent or the subject of an order for relief in bankruptcy.

(3) When the listed subcontractor fails or refuses to perform his or her subcontract.

(4) When the listed subcontractor fails or refuses to meet the bond requirements of the prime contractor as set forth in Section 4108.

(5) When the prime contractor demonstrates to the awarding authority, or its duly authorized officer, subject to the further provisions set forth in Section 4107.5, that the name of the subcontractor was listed as the result of an inadvertent clerical error.

(6) When the listed subcontractor is not licensed pursuant to the Contractors License Law.

(7) When the awarding authority, or its duly authorized officer, determines that the work performed by the listed subcontractor is substantially unsatisfactory and not in substantial accordance with the plans and specifications, or that the subcontractor is substantially delaying or disrupting the progress of the work.

(8) When the listed subcontractor is ineligible to work on a public works project pursuant to Section 1777.1 or 1777.7 of the Labor Code.

(9) When the awarding authority determines that a listed subcontractor is not a responsible contractor.

Prior to approval of the prime contractor’s request for the substitution, the awarding authority, or its duly authorized officer, shall give notice in writing to the listed subcontractor of the prime contractor’s request to substitute and of the reasons for the request. The notice shall be served by certified or registered mail to the last known address of the subcontractor. The listed subcontractor who has been so notified has five working days within which to submit written objections to the substitution to the awarding authority. Failure to file these written objections constitutes the listed subcontractor’s consent to the substitution.

If written objections are filed, the awarding authority shall give notice in writing of at least five working days to the listed subcontractor of a hearing by the awarding authority on the prime contractor’s request for substitution.

(b) Permit a subcontract to be voluntarily assigned or transferred or allow it to be performed by anyone other than the original subcontractor listed in the original bid, without the consent of the awarding authority, or its duly authorized officer.

(c) Other than in the performance of “change orders” causing changes or deviations from the original contract, sublet or subcontract any portion of the work in excess of one-half of 1 percent of the prime contractor’s total bid as to which his or her original bid did not designate a subcontractor.

(Amended by Stats. 2009, Ch. 500, Sec. 58. (AB 1059) Effective January 1, 2010.)

Section 4107.2§Sections

No subcontractor listed by a prime contractor under Section 4104 as furnishing and installing carpeting, shall voluntarily sublet his or her subcontract with respect to any portion of the labor to be performed unless he or she specified the subcontractor in his or her bid for that subcontract to the prime contractor.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4107.5§Sections

The prime contractor as a condition to assert a claim of inadvertent clerical error in the listing of a subcontractor shall within two working days after the time of the prime bid opening by the awarding authority give written notice to the awarding authority and copies of that notice to both the subcontractor he or she claims to have listed in error and the intended subcontractor who had bid to the prime contractor prior to bid opening.

Any listed subcontractor who has been notified by the prime contractor in accordance with this section as to an inadvertent clerical error shall be allowed six working days from the time of the prime bid opening within which to submit to the awarding authority and to the prime contractor written objection to the prime contractor’s claim of inadvertent clerical error. Failure of the listed subcontractor to file the written notice within the six working days shall be primary evidence of his or her agreement that an inadvertent clerical error was made.

The awarding authority shall, after a public hearing as provided in Section 4107 and in the absence of compelling reasons to the contrary, consent to the substitution of the intended subcontractor:

(a) If (1) the prime contractor, (2) the subcontractor listed in error, and (3) the intended subcontractor each submit an affidavit to the awarding authority along with such additional evidence as the parties may wish to submit that an inadvertent clerical error was in fact made, provided that the affidavits from each of the three parties are filed within eight working days from the time of the prime bid opening, or

(b) If the affidavits are filed by both the prime contractor and the intended subcontractor within the specified time but the subcontractor whom the prime contractor claims to have listed in error does not submit within six working days, to the awarding authority and to the prime contractor, written objection to the prime contractor’s claim of inadvertent clerical error as provided in this section.

If the affidavits are filed by both the prime contractor and the intended subcontractor but the listed subcontractor has, within six working days from the time of the prime bid opening, submitted to the awarding authority and to the prime contractor written objection to the prime contractor’s claim of inadvertent clerical error, the awarding authority shall investigate the claims of the parties and shall hold a public hearing as provided in Section 4107 to determine the validity of those claims. Any determination made shall be based on the facts contained in the declarations submitted under penalty of perjury by all three parties and supported by testimony under oath and subject to cross-examination. The awarding authority may, on its own motion or that of any other party, admit testimony of other contractors, any bid registries or depositories, or any other party in possession of facts which may have a bearing on the decision of the awarding authority.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4107.7§Sections

If a contractor who enters into a contract with a public entity for investigation, removal or remedial action, or disposal relative to the release or presence of a hazardous material or hazardous waste fails to pay a subcontractor registered as a hazardous waste hauler pursuant to Section 25163 of the Health and Safety Code within 10 days after the investigation, removal or remedial action, or disposal is completed, the subcontractor may serve a stop notice upon the public entity in accordance with Chapter 4 (commencing with Section 9350) of Title 3 of Part 6 of Division 4 of the Civil Code.

(Amended by Stats. 2010, Ch. 697, Sec. 43. (SB 189) Effective January 1, 2011. Operative July 1, 2012, by Sec. 105 of Ch. 697.)

Section 4108§Sections

(a) It shall be the responsibility of each subcontractor submitting bids to a prime contractor to be prepared to submit a faithful performance and payment bond or bonds if so requested by the prime contractor.

(b) In the event any subcontractor submitting a bid to a prime contractor does not, upon the request of the prime contractor and at the expense of the prime contractor at the established charge or premium therefor, furnish to the prime contractor a bond or bonds issued by an admitted surety wherein the prime contractor shall be named the obligee, guaranteeing prompt and faithful performance of the subcontract and the payment of all claims for labor and materials furnished or used in and about the work to be done and performed under the subcontract, the prime contractor may reject the bid and make a substitution of another subcontractor subject to Section 4107.

(c) (1) The bond or bonds may be required under this section only if the prime contractor in his or her written or published request for subbids clearly specifies the amount and requirements of the bond or bonds.

(2) If the expense of the bond or bonds required under this section is to be borne by the subcontractor, that requirement shall also be specified in the prime contractor’s written or published request for subbids.

(3) The prime contractor’s failure to specify bond requirements, in accordance with this subdivision, in the written or published request for subbids shall preclude the prime contractor from imposing bond requirements under this section.

(Amended by Stats. 1991, Ch. 754, Sec. 1.)

Section 4109§Sections

Subletting or subcontracting of any portion of the work in excess of one-half of 1 percent of the prime contractor’s total bid as to which no subcontractor was designated in the original bid shall only be permitted in cases of public emergency or necessity, and then only after a finding reduced to writing as a public record of the awarding authority setting forth the facts constituting the emergency or necessity.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4110§Sections

A prime contractor violating any of the provisions of this chapter violates his or her contract and the awarding authority may exercise the option, in its own discretion, of (1) canceling his or her contract or (2) assessing the prime contractor a penalty in an amount of not more than 10 percent of the amount of the subcontract involved, and this penalty shall be deposited in the fund out of which the prime contract is awarded. In any proceedings under this section the prime contractor shall be entitled to a public hearing and to five days’ notice of the time and place thereof.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4111§Sections

Violation of this chapter by a licensee under Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code constitutes grounds for disciplinary action by the Contractors State License Board, in addition to the penalties prescribed in Section 4110.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4112§Sections

The failure on the part of a contractor to comply with any provision of this chapter does not constitute a defense to the contractor in any action brought against the contractor by a subcontractor.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4113§Sections

As used in this chapter, the word “subcontractor” shall mean a contractor, within the meaning of the provisions of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code, who contracts directly with the prime contractor.

“Prime contractor” shall mean the contractor who contracts directly with the awarding authority.

(Added by Stats. 1986, Ch. 195, Sec. 42.1.)

Section 4114§Sections

The county board of supervisors, when it is the awarding authority, may delegate its functions under Sections 4107 and 4110 to any officer designated by the board.

The authorized officer shall make a written recommendation to the board of supervisors. The board of supervisors may adopt the recommendation without further notice or hearing, or may set the matter for a de novo hearing before the board.

(Amended by Stats. 1989, Ch. 43, Sec. 1.)

Section 5100§Sections

(a) “Public entity” means the state, Regents of the University of California, a county, city and county, city, district, public authority, public agency, and any other political subdivision or public corporation in the state.

(b) “Bid” means any proposal submitted to a public entity in competitive bidding for the construction, alteration, repair, or improvement of any structure, building, road or other improvement of any kind.

(Added by Stats. 1982, Ch. 435, Sec. 2.)

Section 5101§Sections

(a) A bidder shall not be relieved of the bid unless by consent of the awarding authority nor shall any change be made in the bid because of mistake, but the bidder may bring an action against the public entity in a court of competent jurisdiction in the county in which the bids were opened for the recovery of the amount forfeited, without interest or costs. If the plaintiff fails to recover judgment, the plaintiff shall pay all costs incurred by the public entity in the suit, including a reasonable attorney’s fee to be fixed by the court.

(b) If an awarding authority for the state consents to relieve a bidder of a bid because of mistake, the authority shall prepare a report in writing to document the facts establishing the existence of each element required by Section 5103. The report shall be available for inspection as a public record. In the case of the University of California or a California State University, the report shall be filed with the regents and the trustees, respectively, and shall be available as a public record.

(Amended by Stats. 1994, Ch. 726, Sec. 21. Effective September 22, 1994.)

Section 5102§Sections

The complaint shall be filed, and summons served on the director of the department or the chief of the division or other head of the public entity under which the work is to be performed or an appearance made, within 90 days after the opening of the bid; otherwise, the action shall be dismissed.

(Added by Stats. 1982, Ch. 435, Sec. 2.)

Section 5103§Sections

The bidder shall establish to the satisfaction of the court that:

(a) A mistake was made.

(b) He or she gave the public entity written notice within five working days, excluding Saturdays, Sundays, and state holidays, after the opening of the bids of the mistake, specifying in the notice in detail how the mistake occurred.

(c) The mistake made the bid materially different than he or she intended it to be.

(d) The mistake was made in filling out the bid and not due to error in judgment or to carelessness in inspecting the site of the work, or in reading the plans or specifications.

(Amended by Stats. 2005, Ch. 270, Sec. 2. Effective January 1, 2006.)

Section 5104§Sections

Other than the notice to the public entity, no claim is required to be filed before bringing the action.

(Added by Stats. 1982, Ch. 435, Sec. 2.)

Section 5105§Sections

A bidder who claims a mistake or who forfeits his or her bid security shall be prohibited from participating in further bidding on the project on which the mistake was claimed or security forfeited.

(Added by Stats. 1982, Ch. 435, Sec. 2.)

Section 5106§Sections

If the public entity deems it is for its best interest, it may, on refusal or failure of the successful bidder to execute the contract, award it to the second lowest bidder.

If the second lowest bidder fails or refuses to execute the contract, the public entity may likewise award it to the third lowest bidder.

On the failure or refusal of the second or third lowest bidder to whom a contract is so awarded to execute it, his or her bidder’s security shall be likewise forfeited.

(Added by Stats. 1982, Ch. 435, Sec. 2.)

Section 5107§Sections

In all actions brought under the provisions of this chapter, all courts wherein such actions are or may hereafter be pending, shall give such actions preference over all other civil actions therein, in the matter of setting the same for hearing or trial, and in hearing the same, to the end that all such actions shall be quickly heard and determined.

(Added by Stats. 1982, Ch. 435, Sec. 2.)

Section 5110§Sections

(a) When a project for the construction, alteration, repair, or improvement of any structure, building, or road, or other improvement of any kind is competitively bid and any intended or actual award of the contract is challenged, the contract may be entered into pending final decision of the challenge, subject to the requirements of this section. If the contract is later determined to be invalid due to a defect or defects in the competitive bidding process caused solely by the public entity, the contractor who entered into the contract with the public entity shall be entitled to be paid the reasonable cost, specifically excluding profit, of the labor, equipment, materials, and services furnished by the contractor prior to the date of the determination that the contract is invalid if all of the following conditions are met:

(1) The contractor proceeded with construction, alteration, repair, or improvement based upon a good faith belief that the contract was valid.

(2) The public entity has reasonably determined that the work performed is satisfactory.

(3) Contractor fraud did not occur in the obtaining or performance of the contract.

(4) The contract does not otherwise violate statutory or constitutional limitations.

(b) In no event shall payment to the contractor pursuant to this section exceed either of the following:

(1) The contractor’s costs as included in its bid plus the cost of any approved change orders.

(2) The amount of the contract less profit at the point in time the contract is determined to be invalid.

(c) Notwithstanding subdivision (a), this section shall not affect any protest and legal proceedings, whether contractual, administrative, or judicial, to challenge the award of the public works contract and enforce competitive bidding laws, nor affect any rights under Section 337.1 or 337.15 of the Code of Civil Procedure.

(Added by Stats. 2003, Ch. 678, Sec. 2. Effective January 1, 2004.)

Section 6100§Sections

(a) A state agency, as defined in Section 10335.7 that is subject to this code, shall, prior to awarding a contract for work to be performed by a contractor, as defined by Section 7026 of the Business and Professions Code, verify with the Contractors State License Board that the person seeking the contract is licensed in a classification appropriate to the work to be undertaken. Verification as required by this section need only be made once every two years with respect to the same contractor.

(b) In lieu of the verification, the state entity may require the person seeking the contract to present his or her pocket license or certificate of licensure and provide a signed statement which swears, under penalty of perjury, that the pocket license or certificate of licensure presented is his or hers, is current and valid, and is in a classification appropriate to the work to be undertaken.

(Amended by Stats. 2015, Ch. 303, Sec. 419. (AB 731) Effective January 1, 2016.)

Section 6101§Sections

(a) A state agency, as defined in Section 10335.7, that is subject to this code, shall not award a public works or purchase contract to a bidder or contractor, nor shall a bidder or contractor be eligible to bid for or receive a public works or purchase contract, who has, in the preceding five years, been convicted of violating a state or federal law respecting the employment of undocumented immigrants.

(b) For purposes of this section, “immigrant” means a person who is not a citizen or national of the United States.

(Amended by Stats. 2021, Ch. 296, Sec. 55. (AB 1096) Effective January 1, 2022.)

Section 6102§Sections

(a) A contract that was entered into because of an act that would constitute a violation of a state or federal crime relating to bribery of a public official, including, but not limited to, a violation of Section 68 or 86 of the Penal Code is voidable.

(b) This section applies to contracts executed on or after January 1, 2023, including contracts negotiated prior to January 1, 2023.

(Added by Stats. 2022, Ch. 297, Sec. 1. (SB 34) Effective January 1, 2023.)

Section 6106§Sections

(a) Any state agency or department, which is subject to this code, shall follow this section in negotiating fees and executing a contract for professional consulting services of a private architectural, engineering, land surveying, environmental, or construction project management firm.

(b) After providing notification to the successful firm of its selection, the state shall provide written instructions for the negotiations which are to follow. These instructions shall provide the private consulting firm with necessary information which shall allow the negotiations to proceed in an orderly fashion. Negotiations shall begin within 14 days after the successful firm has been notified of its selection or upon receipt of the cost proposal. The contractor should be notified if additional time is necessary to begin negotiations.

(c) Upon the completion of negotiations, the state and the private firm shall proceed to execute a contract so that the contract may be completed by the state within 45 days. The contractor should be notified if additional time is necessary to complete the contract. The state and private firm shall work together to ensure the successful delivery of the requested services in a timely fashion.

(d) In the event that an impasse is reached in negotiations, the state agency or department may terminate negotiations and enter into negotiations with the next most qualified firm as prescribed in Section 4528 of the Government Code.

(Added by Stats. 1990, Ch. 1128, Sec. 2.)

Section 6106.5§Sections

(a) “State agency,” as used in this section, means those departments defined in Section 10106 of the Public Contract Code.

(b) “Contractor,” as used in this section, means “firm,” “architectural, landscape architectural, engineering, environmental, and land surveying services,” “construction project management,” and “environmental services” as defined in Section 4525 of the Government Code.

(c) State agencies shall include a provision in solicitations and in contracts, if the estimated amount to be retained exceeds ten thousand dollars ($10,000), and the retention continues for a period of 60 days beyond the completion of phased services, to permit, upon written request and the expense of the contractor, the payment of retentions earned directly to a state- or federally chartered bank in this state, as the escrow agent. The contractor may direct the investment of the payments into securities, pursuant to subdivision (d), and the contractor shall receive the interest earned on the investments. Upon satisfactory completion of the contract, the contractor shall receive from the escrow agent all securities, interest, and payments received by the escrow agent from the owner, pursuant to the terms of this section. State agencies, relative to contracts entered into prior to the enactment of this section, upon written request of the contractor, and subject to the approval of the state agency, may utilize the provisions of this section.

(d) Securities eligible for investment under this section shall include those listed in Section 16430 of the Government Code, interest-bearing demand deposit accounts, or any other investment mutually agreed to by the contractor and the state agency.

(e) (1) Any contractor who elects to receive interest on moneys withheld in retention by a state agency shall, at the request of any subcontractor, make that option available to the subcontractor regarding any moneys withheld in retention by the contractor from the subcontractor. If the contractor elects to receive interest on any moneys withheld in retention by a state agency, then the subcontractor shall receive the identical rate of interest received by the contractor on any retention moneys withheld from the subcontractor by the contractor, less any actual pro rata costs associated with administering and calculating that interest. In the event that the interest rate is a fluctuating rate, the rate for the subcontractor shall be determined by calculating the interest rate paid during the time that retentions were withheld from the subcontractor. If the contractor elects to substitute securities in lieu of retention, then, by mutual consent of the contractor and subcontractor, the subcontractor may substitute securities in exchange for the release of moneys held in retention by the contractor.

(2) This subdivision shall apply only to those subcontractors performing more than 5 percent of the contractor’s total fee.

(3) No contractor shall require any subcontractor to waive any provision of this section.

(f) An escrow agreement used pursuant to this section shall be null, void, and unenforceable unless it is substantially similar to the following form:

(1) Pursuant to Section 6106.5 of the Public Contract Code of the State of California, upon written request of the contractor, the owner shall make payments of retention earnings required to be withheld by the owner pursuant to the professional consulting services agreement entered into between the owner and contractor for ____ in the amount of ____ dated ____ hereafter referred to as the “contract.”

(2) When the owner makes payment of retentions earned directly to the escrow agent, the escrow agent shall hold them for the benefit of the contractor until such time as the escrow created under this contract is terminated. The contractor may direct the investment of the payments into securities pursuant to Section 6106.5(d) of the Public Contract Code. All terms and conditions of this agreement and the rights and responsibilities of the parties shall be equally applicable and binding when the owner pays the escrow agent directly.

(3) The contractor shall be responsible for paying all fees for the expenses incurred by the escrow agent in administering the escrow account. These expenses and payment terms shall be determined by the contractor and escrow agent.

(4) The contractor shall have the right to withdraw all or any part of the principal or interest in the escrow account only by written notice to the escrow agent accompanied by written authorization from the owner to the escrow agent that the owner consents to the withdrawal of the amount sought to be withdrawn by contractor.

(5) The owner shall have a right to draw upon the escrow account in the event of default by the contractor. Upon seven days’ written notice to the escrow agent from the owner of the default, the escrow agent shall immediately distribute the cash as instructed by the owner.

(6) Upon receipt of written notification from the owner certifying that the contract is final and complete, and that the contractor has complied with all requirements and procedures applicable to the contract, the escrow agent shall release to the contractor all deposits and interest on deposits less escrow fees and charges of the escrow account. The escrow shall be closed immediately upon disbursement of all moneys on deposit and payments of fees and charges.

(7) The escrow agent shall rely on the written notifications from the owner and the contractor pursuant to Sections (1) to (6), inclusive, of this agreement and the owner and contractor shall hold the escrow agent harmless from the escrow agent’s release, conversion, and disbursement of the securities and interest as set forth above.

(8) The names of the persons who are authorized to give written notice or to receive written notice on behalf of the owner and on behalf of the contractor in connection with the foregoing, and exemplars of their respective signatures are as follows:

At the time the escrow account is opened, the owner and contractor shall deliver to the escrow agent a fully executed counterpart of this Agreement.

IN WITNESS WHEREOF, the parties have executed this Agreement by their proper officers on the date first set forth above.

(Amended by Stats. 2005, Ch. 22, Sec. 154. Effective January 1, 2006.)

Section 6107§Sections

(a) As used in this section, “California company” means a sole proprietorship, partnership, joint venture, corporation, or other business entity that was a licensed California contractor on the date when bids for the public contract were opened and meets one of the following:

(1) Has its principal place of business in California.

(2) Has its principal place of business in a state in which there is no local contractor preference on construction contracts.

(3) Has its principal place of business in a state in which there is a local contractor construction preference and the contractor has paid not less than five thousand dollars ($5,000) in sales or use taxes to California for construction related activity for each of the five years immediately preceding the submission of the bid.

(b) (1) When awarding contracts for construction, a state agency shall grant a California company a reciprocal preference as against a nonresident contractor from any state that gives or requires a preference to be given contractors from that state on its public entity construction contracts.

(2) The amount of the reciprocal preference shall be equal to the amount of the preference applied by the state of the nonresident contractor with the lowest responsive bid, except where the resident contractor is eligible for a California small business preference, in which case the preference applied shall be the greater of the two, but not both.

(3) If the contractor submitting the lowest responsive bid is not a California company and has its principal place of business in any state that gives or requires the giving of a preference on its public entity construction contracts to contractors from that state, and if a California company has also submitted a responsive bid, and, with the benefit of the reciprocal preference, the California company’s bid is equal to or less than the original lowest responsive bid, the public entity shall award the contract to the California company at its submitted bid price.

(c) (1) The bidder shall certify, under penalty of perjury, that the bidder qualifies as a California company.

(2) A nonresident contractor shall, at the time of bidding, disclose to the awarding agency any and all bid preferences provided to the nonresident contractor by the state or country in which the nonresident contractor has its principal place of business.

(d) The reciprocal preference is waived if the certification described in paragraph (1) of subdivision (c) does not appear on the bid.

(e) This section does not apply if application of this section might jeopardize the receipt of federal funds or the nonresident contractor certifies, under penalty of perjury, in its bid that its state of residency does not give a preference for contractors from that state on its public entity construction contracts.

(f) “Construction related activity” shall include, without limitation, any activity for which a California contractors’ license is required.

(Amended by Stats. 1996, Ch. 279, Sec. 1. Effective January 1, 1997.)

Section 6108§Sections

(a) (1) Every contract entered into by any state agency for the procurement or laundering of apparel, garments, or corresponding accessories, or the procurement of equipment, materials, or supplies, other than procurement related to a public works contract, shall require that a contractor certify that no apparel, garments, corresponding accessories, equipment, materials, or supplies furnished to the state pursuant to the contract have been laundered or produced in whole or in part by sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive forms of child labor, or exploitation of children in sweatshop labor, or with the benefit of sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive forms of child labor, or exploitation of children in sweatshop labor. The contractor shall agree to comply with this provision of the contract.

(2) The contract shall specify that the contractor is required to cooperate fully in providing reasonable access to the contractor’s records, documents, agents, employees, or premises if reasonably required by authorized officials of the contracting agency, the Department of Industrial Relations, or the Department of Justice determine the contractor’s compliance with the requirements under paragraph (1).

(b) (1) Any contractor contracting with the state who knew or should have known that the apparel, garments, corresponding accessories, equipment, materials, or supplies furnished to the state were laundered or produced in violation of the conditions specified in subdivision (a) when entering into a contract pursuant to subdivision (a), may, subject to subdivision (c), have any or all of the following sanctions imposed:

(A) The contract under which the prohibited apparel, garments, or corresponding accessories, equipment, materials, or supplies were laundered or provided may be voided at the option of the state agency to which the equipment, materials, or supplies were provided.

(B) The contractor may be assessed a penalty that shall be the greater of one thousand dollars ($1,000) or an amount equaling 20 percent of the value of the apparel, garments, corresponding accessories, equipment, materials, or supplies that the state agency demonstrates were produced in violation of the conditions specified in paragraph (1) of subdivision (a) and that were supplied to the state agency under the contract.

(C) The contractor may be removed from the bidder’s list for a period not to exceed 360 days.

(2) Any moneys collected pursuant to this subdivision shall be deposited into the General Fund.

(c) (1) When imposing the sanctions described in subdivision (b), the contracting agency shall notify the contractor of the right to a hearing, if requested, within 15 days of the date of the notice. The hearing shall be before an administrative law judge of the Office of Administrative Hearings in accordance with the procedures specified in Chapter 5 (commencing with Section 11500) of Part 1 of Division 3 of Title 2 of the Government Code. The administrative law judge shall take into consideration any measures the contractor has taken to ensure compliance with this section, and may waive any or all of the sanctions if it is determined that the contractor has acted in good faith.

(2) The agency shall be assessed the cost of the administrative hearing, unless the agency has prevailed in the hearing, in which case the contractor shall be assessed the cost of the hearing.

(d) (1) Any state agency that investigates a complaint against a contractor for violation of this section may limit its investigation to evaluating the information provided by the person or entity submitting the complaint and the information provided by the contractor.

(2) Whenever a contracting officer of the contracting agency has reason to believe that the contractor failed to comply with paragraph (1) of subdivision (a), the agency shall refer the matter for investigation to the head of the agency and, as the head of the agency determines appropriate, to either the Director of Industrial Relations or the Department of Justice.

(e) (1) For purposes of this section, “forced labor” shall have the same meaning as in Section 1307 of Title 19 of the United States Code.

(2) “Abusive forms of child labor” means any of the following:

(A) All forms of slavery or practices similar to slavery, such as the sale and trafficking of children, debt bondage, and serfdom and forced or compulsory labor, including forced or compulsory recruitment of children for use in armed conflict.

(B) The use, procuring, or offering of a child for prostitution, for the production of pornography, or for pornographic performances.

(C) The use, procuring, or offering of a child for illicit activities, in particular for the production and trafficking of illicit drugs.

(D) All work or service exacted from or performed by any person under the age of 18 years either under the menace of any penalty for its nonperformance and for which the worker does not offer oneself voluntarily, or under a contract, the enforcement of which can be accomplished by process or penalties.

(E) All work or service exacted from or performed by a child in violation of all applicable laws of the country of manufacture governing the minimum age of employment, compulsory education, and occupational health and safety.

(3) “Exploitation of children in sweatshop labor” means all work or service exacted from or performed by any person under the age of 18 years in violation of more than one law of the country of manufacture governing wage and benefits, occupational health and safety, nondiscrimination, and freedom of association.

(4) “Sweatshop labor” means all work or service exacted from or performed by any person in violation of more than one law of the country of manufacture governing wages, employee benefits, occupational health, occupational safety, nondiscrimination, or freedom of association.

(5) “Apparel, garments, or corresponding accessories” includes, but is not limited to, uniforms.

(6) Notwithstanding any other provision of this section, “forced labor” and “convict labor” do not include work or services performed by an inmate or a person employed by the California Correctional Training and Rehabilitation Authority.

(7) “State agency” means any state agency in this state.

(f) (1) On or before February 1, 2004, the Department of Industrial Relations shall establish a contractor responsibility program, including a Sweatfree Code of Conduct, to be signed by all bidders on state contracts and subcontracts. Any state agency responsible for procurement shall ensure that the Sweatfree Code of Conduct is available for public review at least 30 calendar days between the dates of receipt and the final award of the contract. The Sweatfree Code of Conduct shall list the requirements that contractors are required to meet, as set forth in subdivision (g).

(2) Upon implementation in the manner described in paragraph (4), every contract entered into by any state agency for the procurement or laundering of apparel, garments, or corresponding accessories, or for the procurement of equipment or supplies, shall require that the contractor certify in accordance with the Sweatfree Code of Conduct that no apparel, garments, or corresponding accessories, or equipment, materials, or supplies, furnished to the state pursuant to the contract have been laundered or produced, in whole or in part, by sweatshop labor.

(3) The appropriate procurement agency, in consultation with the Director of Industrial Relations, shall employ a phased and targeted approach to implementing the Sweatfree Code of Conduct. Sweatfree Code of Conduct procurement policies involving apparel, garments, and corresponding accessories may be permitted a phasein period of up to one year for purposes of feasibility and providing sufficient notice to contractors and the general public. The appropriate procurement agency, in consultation with the Director of Industrial Relations, shall target other procurement categories based on the magnitude of verified sweatshop conditions and the feasibility of implementation, and may set phasein goals and timetables of up to three years to achieve compliance with the principles of the Sweatfree Code of Conduct.

(4) In order to facilitate compliance with the Sweatfree Code of Conduct, the Department of Industrial Relations shall explore mechanisms employed by other governmental entities, including, but not limited to, New Jersey Executive Order No. 20, of 2002, to ensure that businesses that contract with this state are in compliance with this section and any regulations or requirements promulgated in conformance with this section, as amended by Section 2 of Chapter 711 of the Statutes of 2003. The mechanisms explored may include, but not be limited to, authorization to contract with a competent nonprofit organization that is neither funded nor controlled, in whole or in part, by a corporation that is engaged in the procurement or laundering of apparel, garments, or corresponding accessories, or the procurement of equipment, materials, or supplies. The Department of Industrial Relations, in complying with this paragraph, shall also consider any feasible and cost-effective monitoring measures that will encourage compliance with the Sweatfree Code of Conduct.

(5) To ensure public access and confidence, the Department of Industrial Relations shall ensure public awareness and access to proposed contracts by postings on the Internet and through communication to advocates for garment workers, unions, and other interested parties. The appropriate agencies shall establish a mechanism for soliciting and reviewing any information indicating violations of the Sweatfree Code of Conduct by prospective or current bidders, contractors, or subcontractors. The agencies shall make their findings public when they reject allegations against bidding or contracting parties.

(6) Contractors shall ensure that their subcontractors comply in writing with the Sweatfree Code of Conduct, under penalty of perjury. Contractors shall attach a copy of the Sweatfree Code of Conduct to the certification required by subdivision (a).

(g) No state agency may enter into a contract with any contractor unless the contractor meets the following requirements:

(1) Contractors and subcontractors in California shall comply with all appropriate state laws concerning wages, workplace safety, rights to association and assembly, and nondiscrimination standards as well as appropriate federal laws. Contractors based in other states in the United States shall comply with all appropriate laws of their states and appropriate federal laws. For contractors whose locations for manufacture or assembly are outside the United States, those contractors shall ensure that their subcontractors comply with the appropriate laws of countries where the facilities are located.

(2) Contractors and subcontractors shall maintain a policy of not terminating any employee except for just cause, and employees shall have access to a mediator or to a mediation process to resolve certain workplace disputes that are not regulated by the National Labor Relations Board.

(3) Contractors and subcontractors shall ensure that workers are paid, at a minimum, wages and benefits in compliance with applicable local, state, and national laws of the jurisdiction in which the labor, on behalf of the contractor or subcontractor, is performed. Whenever a state agency expends funds for the procurement or laundering of apparel, garments, or corresponding accessories, or the procurement of equipment, materials, or supplies, other than procurement related to a public works contract, the applicable labor standards established by the local jurisdiction through the exercise of either local police powers or local spending powers in which the labor, in compliance with the contract or purchase order for which the expenditure is made, is performed shall apply with regard to the contract or purchase order for which the expenditure is made, unless the applicable local standards are in conflict with, or are explicitly preempted by, state law. A state agency may not require, as a condition for the receipt of state funds or assistance, that a local jurisdiction refrain from applying the labor standards that are otherwise applicable to that local jurisdiction. The Department of Industrial Relations may, without incurring additional expenses, access information from any nonprofit organization, including, but not limited to, the World Bank, that gathers and disseminates data with respect to wages paid throughout the world, to allow the Department of Industrial Relations to determine whether contractors and subcontractors are compensating their employees at a level that enables those employees to live above the applicable poverty level.

(4) All contractors and subcontractors shall comply with the overtime laws and regulations of the country in which their employees are working.

(5) All overtime hours shall be worked voluntarily. Workers shall be compensated for overtime at either (A) the rate of compensation for regular hours of work, or (B) as legally required in the country of manufacture, whichever is greater.

(6) No person may be employed who is younger than the legal age for children to work in the country in which the facility is located. In no case may children under the age of 15 years be employed in the manufacturing process. Where the age for completing compulsory education is higher than the standard for the minimum age of employment, the age for completing education shall apply to this section.

(7) There may be no form of forced labor of any kind, including slave labor, prison labor, indentured labor, or bonded labor, including forced overtime hours.

(8) The work environment shall be safe and healthy and, at a minimum, be in compliance with relevant local, state, and national laws. If residential facilities are provided to workers, those facilities shall be safe and healthy as well.

(9) There may be no discrimination in hiring, salary, benefits, performance evaluation, discipline, promotion, retirement, or dismissal on the basis of age, sex, pregnancy, maternity leave status, marital status, race, nationality, country of origin, ethnic origin, disability, sexual orientation, gender identity, religion, or political opinion.

(10) No worker may be subjected to any physical, sexual, psychological, or verbal harassment or abuse, including corporal punishment, under any circumstances, including, but not limited to, retaliation for exercising their right to free speech and assembly.

(11) No worker may be forced to use contraceptives or take pregnancy tests. No worker may be exposed to chemicals, including glues and solvents, that endanger reproductive health.

(12) Contractors and bidders shall list the names and addresses of each subcontractor to be utilized in the performance of the contract, and list each manufacturing or other facility or operation of the contractor or subcontractor for performance of the contract. The list, which shall be maintained and updated to show any changes in subcontractors during the term of the contract, shall provide company names, owners or officers, addresses, telephone numbers, e-mail addresses, and the nature of the business association.

(h) Any person who certifies as true any material matter pursuant to this section that they know to be false is guilty of a misdemeanor.

(i) The provisions of this section, as amended by Section 2 of Chapter 711 of the Statutes of 2003, shall be in addition to any other provisions that authorize the prosecution and enforcement of local labor laws and may not be interpreted to prohibit a local prosecutor from bringing a criminal or civil action against an individual or business that violates the provisions of this section.

(j) (1) The certification requirements set forth in subdivisions (a) and (f) do not apply to a credit card purchase of goods of two thousand five hundred dollars ($2,500) or less.

(2) The total amount of exemption authorized herein shall not exceed seven thousand five hundred dollars ($7,500) per year for each company from which a state agency is purchasing goods by credit card. It shall be the responsibility of each state agency to monitor the use of this exemption and adhere to these restrictions on these purchases.

(Amended by Stats. 2025, Ch. 241, Sec. 63. (SB 857) Effective January 1, 2026.)

Section 6109§Sections

(a) A public entity, as defined in Section 1100, may not permit a contractor or subcontractor who is ineligible to bid or work on, or be awarded, a public works project pursuant to Section 1777.1 or 1777.7 of the Labor Code to bid on, be awarded, or perform work as a subcontractor on, a public works project. Every public works project shall contain a provision prohibiting a contractor from performing work on a public works project with a subcontractor who is ineligible to perform work on the public works project pursuant to Section 1777.1 or 1777.7 of the Labor Code.

(b) Any contract on a public works project entered into between a contractor and a debarred subcontractor is void as a matter of law. A debarred subcontractor may not receive any public money for performing work as a subcontractor on a public works contract, and any public money that may have been paid to a debarred subcontractor by a contractor on the project shall be returned to the awarding body. The contractor shall be responsible for the payment of wages to workers of a debarred subcontractor who has been allowed to work on the project.

(Added by Stats. 1998, Ch. 443, Sec. 3. Effective January 1, 1999.)

Section 10160§Sections

The department may require from prospective bidders answers to questions contained in a standard form of questionnaire and financial statement including a complete statement of the prospective bidder’s financial ability and experience in performing public works. When completed, the questionnaire and financial statement shall be verified under oath by the bidder in the manner in which pleadings in civil actions are verified.

Whenever prequalification is required of any bidder on a contract, it shall be required for all prospective bidders to that contract.

(Amended by Stats. 1993, Ch. 471, Sec. 1. Effective January 1, 1994.)

Section 10161§Sections

The department may also require from prospective bidders the completion, under penalty of perjury, of a standard form of questionnaire concerning the past safety record of each prospective bidder, any officer of such bidder, and any managing employee of such bidder. The department may refuse to prequalify any prospective bidder who fails to submit a completed questionnaire when required, or for the reason that the information contained in the submitted questionnaire or otherwise known to the department indicates a continuing unsatisfactory safety record.

The director of the department shall prescribe guidelines listing criteria which will be utilized administratively in determining an unsatisfactory safety record. A refusal by the department to prequalify a prospective bidder shall be issued only after the department has granted such bidder a hearing.

This section shall in no way abridge or restrict the right of the department to later determine whether the low bidder on a particular project is the lowest responsible bidder for purposes of award of the contract, including the holding of hearings thereon.

The Director of Industrial Relations shall approve the standard form of questionnaire and the guidelines listing criteria which will be utilized administratively by the department in determining an unsatisfactory safety record prior to their use by the department.

(Enacted by Stats. 1981, Ch. 306.)

Section 10162§Sections

The department shall require from all prospective bidders the completion, under penalty of perjury, of a standard form of questionnaire inquiring whether such prospective bidder, any officer of such bidder, or any employee of such bidder who has a proprietary interest in such bidder, has ever been disqualified, removed, or otherwise prevented from bidding on, or completing a federal, state, or local government project because of a violation of law or a safety regulation, and if so to explain the circumstances.

A bid may be rejected on the basis of a bidder, any officer of such bidder, or any employee of such bidder who has a proprietary interest in such bidder, having been disqualified, removed, or otherwise prevented from bidding on, or completing a federal, state, or local project because of a violation of law or a safety regulation.

(Enacted by Stats. 1981, Ch. 306.)

Section 10163§Sections

The department shall adopt and apply a uniform system of rating bidders, on the basis of the standard questionnaires and financial statements, in respect to the size of the contracts upon which each bidder is qualified to bid. When bids for more than one project are to be received at the same bid opening, the department may permit a bidder to submit bids for each project within such bidder’s prequalification rating, even though such rating is insufficient to permit the bidder to be awarded the contract for each project bid upon.

In no event shall any bidder be awarded a contract if such contract award would result in the bidder having under contract work for which prequalification is required in excess of that authorized by his prequalification rating. In determining whether an award of a contract would result in a bidder having under contract work in excess of that authorized by his prequalification rating, the department may use its estimated cost of such contract rather than the amount of the bidder’s bid. If the department determines that a bidder would be awarded the contract for two or more projects but cannot be awarded the contract for all such projects because of the inadequacy of his prequalification rating, the department shall determine which of the bids of such bidder are to be accepted and the contract awarded thereon and which of the bids of such bidder are to be disregarded. In making its decision the department shall be guided by the combination of contract awards which will result in the lowest total cost for the projects involved.

(Enacted by Stats. 1981, Ch. 306.)

Section 10164§Sections

In all state projects where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with the laws of this state. However, at the time the contract is awarded, the contractor shall be properly licensed in accordance with the laws of this state. The contract shall not be awarded unless the state agency has verified that the contractor has a valid license in the appropriate classification for the work performed. Any bidder or contractor not so licensed shall be subject to all legal penalties imposed by law, including, but not limited to, any appropriate disciplinary action by the Contractors State License Board. The department shall include a statement to that effect in the standard form of prequalification questionnaire and financial statement. Failure of the bidder to obtain proper and adequate licensing for an award of a contract shall constitute a failure to execute the contract as provided in Section 10181 and shall result in the forfeiture of the security of the bidder.

(Amended by Stats. 1994, Ch. 432, Sec. 1. Effective January 1, 1995.)

Section 10165§Sections

The questionnaires and financial statements are not public records and are not open to public inspection.

(Enacted by Stats. 1981, Ch. 306.)

Section 10166§Sections

The department shall furnish to each bidder a standard proposal form, which, when filled out and executed may be submitted as his bid. Bids not presented on forms so furnished shall be disregarded. The department shall not furnish proposal forms to any person who is required to submit and has not submitted a questionnaire and financial statement for prequalification at least five days prior to the date fixed for publicly opening sealed bids and been prequalified for at least one day prior to that date.

(Enacted by Stats. 1981, Ch. 306.)

Section 10167§Sections

(a) All bids shall be presented under sealed cover and accompanied by one of the following forms of bidder’s security:

(1) An electronic bidder’s bond by an admitted surety insurer submitted using an electronic registry service approved by the department advertising the contract.

(2) A signed bidder’s bond by an admitted surety insurer received by the department advertising the contract.

(3) Cash, a cashier’s check, or certified check received by, and made payable to, the director of the department advertising the contract.

(b) The required bidder’s security shall be in an amount equal to at least 10 percent of the amount bid. A bid shall not be considered unless one of the forms of bidder’s security is enclosed with it.

(c) All bids submitted pursuant to this section shall also comply with the provisions of Section 1601 of the Public Contract Code.

(Amended by Stats. 2012, Ch. 290, Sec. 3. (AB 1671) Effective January 1, 2013.)

Section 10168§Sections

Whether or not bids are opened exactly at the time fixed in the public notice for opening bids, a bid shall not be received after that time.

(Enacted by Stats. 1981, Ch. 306.)

Section 10169§Sections

Any bid may be withdrawn at any time prior to the time fixed in the public notice for the opening of bids only by written request for the withdrawal of the bid filed with the director of the department or the chief of the division under which the work is to be performed. The request shall be executed by the bidder or his duly authorized representative. The withdrawal of a bid does not prejudice the right of the bidder to file a new bid.

This section does not authorize the withdrawal of any bid after the time fixed in the public notice for the opening of bids.

(Enacted by Stats. 1981, Ch. 306.)

Section 10220§Sections

Every contract awarded under this part shall be submitted to the Attorney General or the attorney appointed according to law and authorized to represent the department under which it is to be performed. Such a contract is not binding on the state until the appropriate attorney finds it to be in accordance with the requirements of this chapter, and endorses such finding thereon.

A certified copy of each contract shall be filed with the Controller, but the failure so to file does not invalidate it.

(Enacted by Stats. 1981, Ch. 306.)

Section 10221§Sections

Every contract shall provide for the filing of separate performance and payment bonds by the contractor in the form of bonds executed by an admitted surety insurer and not deposits in lieu of bond, subject to the approval of the department.

(Amended by Stats. 1982, Ch. 517, Sec. 348.4.)

Section 10222§Sections

(a) Each bond shall equal at least one-half of the contract price, except as otherwise provided in Section 9554 of the Civil Code, in the California Toll Bridge Authority Act (Chapter 1 (commencing with Section 30000) of Division 7 of the Streets and Highways Code), or in subdivision (b).

(b) Notwithstanding subdivision (a), for projects with a contract price greater than two hundred fifty million dollars ($250,000,000), the Department of Transportation shall have the discretion to specify that the payment bond shall equal not less than one-half of the contract price or five hundred million dollars ($500,000,000), whichever is less.

(Amended by Stats. 2010, Ch. 697, Sec. 45. (SB 189) Effective January 1, 2011. Operative July 1, 2012, by Sec. 105 of Ch. 697.)

Section 10223§Sections

The payment bond shall secure the payment of the claims of laborers, mechanics or materialmen employed on the work under the contract and shall contain all other provisions required by law.

(Enacted by Stats. 1981, Ch. 306.)

Section 10224§Sections

The performance bond shall guarantee the faithful performance of the contract by the contractor.

(Enacted by Stats. 1981, Ch. 306.)

Section 10225§Sections

No payment shall be made upon the contract to the contractor or any assignee of the contractor until any order by the director that a sufficient surety be substituted on the bond or that a new, additional, or supplemental bond be given, is satisfied. No cancellation of or withdrawal of a surety from a bond is effective unless approved by the director.

(Amended by Stats. 1982, Ch. 517, Sec. 348.5.)

Section 10226§Sections

Every contract shall contain a provision in regard to the time when the whole or any specified portion of the work contemplated shall be completed, and shall provide that for each day completion is delayed beyond the specified time, the contractor shall forfeit and pay to the state a specified sum of money, to be deducted from any payments due or to become due to the contractor. The sum so specified is valid as liquidated damages unless manifestly unreasonable under the circumstances existing at the time the contract was made. A contract for a road project, flood control project, or project involving facilities of the State Water Resources Development System may also provide for the payment of extra compensation to the contractor, as a bonus for completion prior to the specified time, the provision, if used, to be included in the specifications and to clearly set forth the basis for the payment.

(Amended by Stats. 1990, Ch. 1044, Sec. 1.5. Effective September 19, 1990.)

Section 10227§Sections

Every contract shall provide that the department may make changes in the plans and specifications pursuant to this part.

(Enacted by Stats. 1981, Ch. 306.)

Section 10230§Sections

Every contract subject to this part, for which disabled veteran business enterprise participation is included in the bid, shall contain a provision requiring the contractor to comply with rules, regulations, ordinances, and statutes that apply to the California Disabled Veteran Business Enterprise Program as defined in Section 999 of the Military and Veterans Code, including, but not limited to, the requirements of subdivision (d) of Section 999.5 of the Military and Veterans Code.

(Added by Stats. 2019, Ch. 676, Sec. 5. (AB 230) Effective January 1, 2020.)

Section 10231§Sections

Every contract subject to this part shall contain a provision requiring each contractor to comply with all air pollution control rules, regulations, ordinances, and statutes which apply to any work performed pursuant to the contract, including any air pollution control rules, regulations, ordinances, and statutes specified in Section 11017 of the Government Code.

(Enacted by Stats. 1981, Ch. 306.)

Section 10232§Sections

Every contract shall contain a statement by which the contractor swears under penalty of perjury that no more than one final, unappealable finding of contempt of court by a federal court has been issued against the contractor within the immediately preceding two-year period because of the contractor’s failure to comply with an order of a federal court which orders the contractor to comply with an order of the National Labor Relations Board. For purposes of this section, a finding of contempt does not include any finding which has been vacated, dismissed, or otherwise removed by the court because the contractor has complied with the order which was the basis for the finding. The state may rescind any contract in which the contractor falsely swears to the truth of the statement required by this section.

(Added by Stats. 1982, Ch. 466, Sec. 89.)